Serving Bryan, TX and surrounding areas. (979) 359-2224
Effective date: January 1, 2026
By using the website located at bryansunroomcontractor.com, by submitting a contact or estimate request, or by entering into a written agreement for services with Bryan Sunrooms & Patios ("we," "us," or "our"), you agree to be bound by these Terms and Conditions. If you do not agree, do not use our website or engage our services.
These terms apply to all visitors to our website and to all customers who engage us for services. They supplement - and do not replace - any written contract signed between you and Bryan Sunrooms & Patios for a specific project.
Bryan Sunrooms & Patios provides residential sunroom construction, patio enclosure installation, screen room installation, and related outdoor living services to homeowners in Bryan, TX and surrounding communities. Services are performed by our team or qualified subcontractors working under our direction and supervision.
We do not provide emergency repair services. All projects are subject to scheduling availability, permit requirements, and site conditions. We reserve the right to decline any project that we determine is not within our scope of work or that cannot be completed to our quality standards.
All estimates provided by Bryan Sunrooms & Patios are based on the scope of work described at the time of the site visit and the written estimate. Estimates are not final contracts. A written contract signed by both parties constitutes the binding agreement for a project.
Estimate prices are valid for 30 days from the date of issuance unless otherwise stated in writing. Prices may change if the scope of work changes, if material costs change significantly, or if site conditions discovered after work begins require additional labor or materials.
We will notify you in writing before performing any work that would increase the project cost beyond the original estimate. You have the right to approve or decline any change in scope before additional work proceeds.
Project start dates are estimates based on our current schedule and permit timelines. We will notify you if your start date needs to change due to weather, permit delays, material availability, or other factors outside our control.
If you need to cancel or reschedule a project after signing a contract, please notify us in writing as early as possible. Deposits are non-refundable unless stated otherwise in your written contract. We reserve the right to charge for materials ordered or work performed prior to cancellation.
We reserve the right to stop work on a project if site conditions become unsafe, if required permits are not in place, or if payment obligations are not met on schedule.
Payment terms are set out in your written project contract. Typically, we require a deposit before work begins, progress payments at defined milestones, and a final payment upon project completion. Specific amounts and timing are stated in the contract.
Final payment is due upon completion of the project and the final walkthrough. If payment is not received within the timeframe specified in your contract, we reserve the right to charge a late fee and to pursue collection through lawful means. All work remains the property of Bryan Sunrooms & Patios until payment is received in full.
We accept payment methods specified in your contract. We do not waive any payment obligation because you are dissatisfied with a portion of the work - disputes must be raised in writing before final payment is due.
Bryan Sunrooms & Patios handles building permit applications for projects that require them, including the submission of plans to the City of Bryan Development Services or other applicable authorities. You are responsible for obtaining any required homeowners association approvals before work begins.
You represent that you have the legal right to authorize the work described in your project contract on the property where services will be performed. You agree to provide reasonable access to your property during scheduled work hours.
Bryan Sunrooms & Patios warrants that all work will be performed in a workmanlike manner consistent with applicable building standards. Any specific warranty terms - including duration and coverage - will be stated in your written project contract.
Warranties do not cover damage caused by events outside our control, including but not limited to severe weather, flooding, acts of God, homeowner modifications to the completed work, or lack of routine maintenance. Manufacturer warranties on materials and products are passed through to you as the homeowner and are subject to the manufacturer's terms.
Except as expressly stated in your written contract, we make no other warranties, express or implied, including any implied warranty of merchantability or fitness for a particular purpose.
To the fullest extent permitted by applicable law, Bryan Sunrooms & Patios's total liability to you for any claim arising from our services or this website shall not exceed the total amount you paid us for the project giving rise to the claim.
In no event shall Bryan Sunrooms & Patios be liable for any indirect, incidental, special, or consequential damages, including lost profits, loss of use, or damage to property not directly caused by our work, even if we have been advised of the possibility of such damages.
If a dispute arises between you and Bryan Sunrooms & Patios, we ask that you contact us first in writing at quotes@bryansunroomcontractor.com so we can work toward a resolution. Most issues can be resolved without formal proceedings.
If a dispute cannot be resolved informally, both parties agree to attempt mediation before pursuing litigation. Any legal action arising from these terms or our services shall be brought in the courts of Texas, and both parties consent to jurisdiction in that venue.
These Terms and Conditions and any dispute arising from your use of our website or services are governed by the laws of the State of Texas, without regard to conflict of law principles.
The content on bryansunroomcontractor.com is provided for general informational purposes. We make no guarantees that information on the site is complete, current, or error-free. We reserve the right to modify or remove any content at any time without notice.
You agree not to use our website for any unlawful purpose, to interfere with its operation, or to attempt unauthorized access to any part of the site or its underlying infrastructure.
We reserve the right to update these Terms and Conditions at any time. When we do, we will revise the effective date at the top of this page. Continued use of our website or services after changes are posted constitutes your acceptance of the updated terms. We encourage you to review this page periodically.
If you have questions about these Terms and Conditions, contact us at:
